Heading , GST Tax Rate and SAC

(i) Construction of affordable residential apartments by a promoter in a Residential Real Estate Project (herein after referred to as RREP) which commences on or after 1st April, 2019 or in an ongoing RREP in respect of which the promoter has not exercised option to pay central tax on construction of apartments at the rates as specified for item (ie) or (if) below, as the case may be, in the manner prescribed therein, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that the central tax at the rate specified in column (4) shall be paid in cash, that is, by debiting the electronic cash ledger only; Provided also that credit of input tax charged on goods and services used in supplying the service hasnot been taken except to the extent as prescribed in Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP;

Provided also that the registered person shall pay, by debit in the electronic credit ledger or electronic cash ledger, an amount equivalent to the input tax credit attributable to construction in a project, time of supply of which is on or after 1st April, 2019, which shall be calculated in the manner as prescribed in the Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP; Provided also that where a registered person (landowner- promoter) who transfers development right or FSI (including additional FSI) to a promoter (developer- promoter) against consideration, wholly or partly, in the form of construction of apartments,-
(i) the developer- promoter shall pay tax on supply of construction of apartments to the landowner- promoter, and
(ii) such landowner – promoter shall be eligible for credit of taxes charged from him by the developer promoter towards the supply of construction of apartments by developer- promoter to him, provided the landowner- promoter further supplies such apartments to his buyers before issuance of completion certificate or first occupation, whichever is earlier, and pays tax on the same which is not less than the amount of tax charged from him on construction of such apartments by the developer- promoter.

Explanation. -
(i) “developer- promoter” is a promoter who constructs or converts a building into apartments or develops a plot for sale,
(ii) “landowner- promoter” is a promoter who transfers the land or development rights or FSI to a developer- promoter for construction of apartments and receives constructed apartments against such transferred rights and sells such apartments to his buyers independently.

Provided also that eighty percent of value of input and input services, [other than services by way of grant of development rights, long term lease of land (against upfront payment in the form of premium, salami, development charges etc.) or FSI (including additional FSI), electricity, high speed diesel, motor spirit, natural gas], used in supplying the service shall be received from registered supplier only;
Provided also that inputs and input services on which tax is paid on reverse charge basis shall be deemed to have been purchased from registered person;
Provided also that where value of input and input services received from registered suppliers during the financial year (or part of the financial year till the date of issuance of completion certificate or first occupation of the project, whichever is earlier) falls short of the said threshold of 80 per cent., tax shall be paid by the promoter on value of input and input services comprising such shortfall at the rate of eighteen percent on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017) shall apply to him as if he is the person liable for paying the tax in relation to the supply of such goods or services or both;
Provided also that notwithstanding anything contained herein above, where cement is received from an unregistered person, the promoter shall pay tax on supply of such cement at the applicable rates on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017), shall apply to him as if he is the person liable for paying the tax in relation to such supply of cement; (Please refer to the illustrations in annexure III)

Explanation. -
1. The promoter shall maintain project wise account of inward supplies from registered and unregistered supplier and calculate tax payments on the shortfall at the end of the financial year and shall submit the same in the prescribed form electronically on the common portal by end of the quarter following the financial year. The tax liability on the shortfall of inward supplies from unregistered person so determined shall be added to his output tax liability in the month not later than the month of June following the end of the financial year.
2. Notwithstanding anything contained in Explanation 1 above, tax on cement received from unregistered person shall be paid in the month in which cement is received.
3. Input Tax Credit not availed shall be reported every month by reporting the same as ineligible credit in GSTR-3B [Row No. 4 (D)(2)].

(ia) Construction of residential apartments other than affordable residential apartments by a promoter in an RREP which commences on or after 1st April, 2019 or in an ongoing RREP in respect of which the promoter has not exercised option to pay central tax on construction of apartments at the rates as specified for item (ie) or (if) below, as the case may be, in the manner prescribed therein, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that the central tax at the rate specified in column (4) shall be paid in cash, that is, by debiting the electronic cash ledger only; Provided also that credit of input tax charged on goods and services used in supplying the service hasnot been taken except to the extent as prescribed in Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP;

Provided also that the registered person shall pay, by debit in the electronic credit ledger or electronic cash ledger, an amount equivalent to the input tax credit attributable to construction in a project, time of supply of which is on or after 1st April, 2019, which shall be calculated in the manner as prescribed in the Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP; Provided also that where a registered person (landowner- promoter) who transfers development right or FSI (including additional FSI) to a promoter (developer- promoter) against consideration, wholly or partly, in the form of construction of apartments,-
(i) the developer- promoter shall pay tax on supply of construction of apartments to the landowner- promoter, and
(ii) such landowner – promoter shall be eligible for credit of taxes charged from him by the developer promoter towards the supply of construction of apartments by developer- promoter to him, provided the landowner- promoter further supplies such apartments to his buyers before issuance of completion certificate or first occupation, whichever is earlier, and pays tax on the same which is not less than the amount of tax charged from him on construction of such apartments by the developer- promoter.

Explanation. -
(i) “developer- promoter” is a promoter who constructs or converts a building into apartments or develops a plot for sale,
(ii) “landowner- promoter” is a promoter who transfers the land or development rights or FSI to a developer- promoter for construction of apartments and receives constructed apartments against such transferred rights and sells such apartments to his buyers independently.

Provided also that eighty percent of value of input and input services, [other than services by way of grant of development rights, long term lease of land (against upfront payment in the form of premium, salami, development charges etc.) or FSI (including additional FSI), electricity, high speed diesel, motor spirit, natural gas], used in supplying the service shall be received from registered supplier only;
Provided also that inputs and input services on which tax is paid on reverse charge basis shall be deemed to have been purchased from registered person;
Provided also that where value of input and input services received from registered suppliers during the financial year (or part of the financial year till the date of issuance of completion certificate or first occupation of the project, whichever is earlier) falls short of the said threshold of 80 per cent., tax shall be paid by the promoter on value of input and input services comprising such shortfall at the rate of eighteen percent on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017) shall apply to him as if he is the person liable for paying the tax in relation to the supply of such goods or services or both;
Provided also that notwithstanding anything contained herein above, where cement is received from an unregistered person, the promoter shall pay tax on supply of such cement at the applicable rates on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017), shall apply to him as if he is the person liable for paying the tax in relation to such supply of cement; (Please refer to the illustrations in annexure III)

Explanation. -
1. The promoter shall maintain project wise account of inward supplies from registered and unregistered supplier and calculate tax payments on the shortfall at the end of the financial year and shall submit the same in the prescribed form electronically on the common portal by end of the quarter following the financial year. The tax liability on the shortfall of inward supplies from unregistered person so determined shall be added to his output tax liability in the month not later than the month of June following the end of the financial year.
2. Notwithstanding anything contained in Explanation 1 above, tax on cement received from unregistered person shall be paid in the month in which cement is received.
3. Input Tax Credit not availed shall be reported every month by reporting the same as ineligible credit in GSTR-3B [Row No. 4 (D)(2)].

(ib) Construction of commercial apartments (shops, offices, godowns etc.) by a promoter in an RREP which commences on or after 1st April, 2019 or in an ongoing RREP in respect of which the promoter has not exercised option to pay central tax on construction of apartments at the rates as specified for item (ie) or (if) below, as the case may be, in the manner prescribed therein, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that the central tax at the rate specified in column (4) shall be paid in cash, that is, by debiting the electronic cash ledger only; Provided also that credit of input tax charged on goods and services used in supplying the service hasnot been taken except to the extent as prescribed in Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP;

Provided also that the registered person shall pay, by debit in the electronic credit ledger or electronic cash ledger, an amount equivalent to the input tax credit attributable to construction in a project, time of supply of which is on or after 1st April, 2019, which shall be calculated in the manner as prescribed in the Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP; Provided also that where a registered person (landowner- promoter) who transfers development right or FSI (including additional FSI) to a promoter (developer- promoter) against consideration, wholly or partly, in the form of construction of apartments,-
(i) the developer- promoter shall pay tax on supply of construction of apartments to the landowner- promoter, and
(ii) such landowner – promoter shall be eligible for credit of taxes charged from him by the developer promoter towards the supply of construction of apartments by developer- promoter to him, provided the landowner- promoter further supplies such apartments to his buyers before issuance of completion certificate or first occupation, whichever is earlier, and pays tax on the same which is not less than the amount of tax charged from him on construction of such apartments by the developer- promoter.

Explanation. -
(i) “developer- promoter” is a promoter who constructs or converts a building into apartments or develops a plot for sale,
(ii) “landowner- promoter” is a promoter who transfers the land or development rights or FSI to a developer- promoter for construction of apartments and receives constructed apartments against such transferred rights and sells such apartments to his buyers independently.

Provided also that eighty percent of value of input and input services, [other than services by way of grant of development rights, long term lease of land (against upfront payment in the form of premium, salami, development charges etc.) or FSI (including additional FSI), electricity, high speed diesel, motor spirit, natural gas], used in supplying the service shall be received from registered supplier only;
Provided also that inputs and input services on which tax is paid on reverse charge basis shall be deemed to have been purchased from registered person;
Provided also that where value of input and input services received from registered suppliers during the financial year (or part of the financial year till the date of issuance of completion certificate or first occupation of the project, whichever is earlier) falls short of the said threshold of 80 per cent., tax shall be paid by the promoter on value of input and input services comprising such shortfall at the rate of eighteen percent on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017) shall apply to him as if he is the person liable for paying the tax in relation to the supply of such goods or services or both;
Provided also that notwithstanding anything contained herein above, where cement is received from an unregistered person, the promoter shall pay tax on supply of such cement at the applicable rates on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017), shall apply to him as if he is the person liable for paying the tax in relation to such supply of cement; (Please refer to the illustrations in annexure III)

Explanation. -
1. The promoter shall maintain project wise account of inward supplies from registered and unregistered supplier and calculate tax payments on the shortfall at the end of the financial year and shall submit the same in the prescribed form electronically on the common portal by end of the quarter following the financial year. The tax liability on the shortfall of inward supplies from unregistered person so determined shall be added to his output tax liability in the month not later than the month of June following the end of the financial year.
2. Notwithstanding anything contained in Explanation 1 above, tax on cement received from unregistered person shall be paid in the month in which cement is received.
3. Input Tax Credit not availed shall be reported every month by reporting the same as ineligible credit in GSTR-3B [Row No. 4 (D)(2)].

(ic) Construction of affordable residential apartments by a promoter in a Real Estate Project (herein after referred to as REP) other than RREP, which commences on or after 1st April, 2019 or in an ongoing REP other than RREP in respect of which the promoter has not exercised option to pay central tax on construction of apartments at the rates as specified for item (ie) or (if) below, as the case may be, in the manner prescribed therein, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that the central tax at the rate specified in column (4) shall be paid in cash, that is, by debiting the electronic cash ledger only; Provided also that credit of input tax charged on goods and services used in supplying the service hasnot been taken except to the extent as prescribed in Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP;

Provided also that the registered person shall pay, by debit in the electronic credit ledger or electronic cash ledger, an amount equivalent to the input tax credit attributable to construction in a project, time of supply of which is on or after 1st April, 2019, which shall be calculated in the manner as prescribed in the Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP; Provided also that where a registered person (landowner- promoter) who transfers development right or FSI (including additional FSI) to a promoter (developer- promoter) against consideration, wholly or partly, in the form of construction of apartments,-
(i) the developer- promoter shall pay tax on supply of construction of apartments to the landowner- promoter, and
(ii) such landowner – promoter shall be eligible for credit of taxes charged from him by the developer promoter towards the supply of construction of apartments by developer- promoter to him, provided the landowner- promoter further supplies such apartments to his buyers before issuance of completion certificate or first occupation, whichever is earlier, and pays tax on the same which is not less than the amount of tax charged from him on construction of such apartments by the developer- promoter.

Explanation. -
(i) “developer- promoter” is a promoter who constructs or converts a building into apartments or develops a plot for sale,
(ii) “landowner- promoter” is a promoter who transfers the land or development rights or FSI to a developer- promoter for construction of apartments and receives constructed apartments against such transferred rights and sells such apartments to his buyers independently.

Provided also that eighty percent of value of input and input services, [other than services by way of grant of development rights, long term lease of land (against upfront payment in the form of premium, salami, development charges etc.) or FSI (including additional FSI), electricity, high speed diesel, motor spirit, natural gas], used in supplying the service shall be received from registered supplier only;
Provided also that inputs and input services on which tax is paid on reverse charge basis shall be deemed to have been purchased from registered person;
Provided also that where value of input and input services received from registered suppliers during the financial year (or part of the financial year till the date of issuance of completion certificate or first occupation of the project, whichever is earlier) falls short of the said threshold of 80 per cent., tax shall be paid by the promoter on value of input and input services comprising such shortfall at the rate of eighteen percent on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017) shall apply to him as if he is the person liable for paying the tax in relation to the supply of such goods or services or both;
Provided also that notwithstanding anything contained herein above, where cement is received from an unregistered person, the promoter shall pay tax on supply of such cement at the applicable rates on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017), shall apply to him as if he is the person liable for paying the tax in relation to such supply of cement; (Please refer to the illustrations in annexure III)

Explanation. -
1. The promoter shall maintain project wise account of inward supplies from registered and unregistered supplier and calculate tax payments on the shortfall at the end of the financial year and shall submit the same in the prescribed form electronically on the common portal by end of the quarter following the financial year. The tax liability on the shortfall of inward supplies from unregistered person so determined shall be added to his output tax liability in the month not later than the month of June following the end of the financial year.
2. Notwithstanding anything contained in Explanation 1 above, tax on cement received from unregistered person shall be paid in the month in which cement is received.
3. Input Tax Credit not availed shall be reported every month by reporting the same as ineligible credit in GSTR-3B [Row No. 4 (D)(2)].

(id) Construction of residential apartments other than affordable residential apartments by a promoter in a REP other than a RREP which commences on or after 1st April, 2019 or in an ongoing REP other than RREP in respect of which the promoter has not exercised option to pay central tax on construction of apartments at the rates as specified for item (ie) or (if) below, as the case may be, in the manner prescribed therein, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that the central tax at the rate specified in column (4) shall be paid in cash, that is, by debiting the electronic cash ledger only; Provided also that credit of input tax charged on goods and services used in supplying the service hasnot been taken except to the extent as prescribed in Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP;

Provided also that the registered person shall pay, by debit in the electronic credit ledger or electronic cash ledger, an amount equivalent to the input tax credit attributable to construction in a project, time of supply of which is on or after 1st April, 2019, which shall be calculated in the manner as prescribed in the Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP; Provided also that where a registered person (landowner- promoter) who transfers development right or FSI (including additional FSI) to a promoter (developer- promoter) against consideration, wholly or partly, in the form of construction of apartments,-
(i) the developer- promoter shall pay tax on supply of construction of apartments to the landowner- promoter, and
(ii) such landowner – promoter shall be eligible for credit of taxes charged from him by the developer promoter towards the supply of construction of apartments by developer- promoter to him, provided the landowner- promoter further supplies such apartments to his buyers before issuance of completion certificate or first occupation, whichever is earlier, and pays tax on the same which is not less than the amount of tax charged from him on construction of such apartments by the developer- promoter.

Explanation. -
(i) “developer- promoter” is a promoter who constructs or converts a building into apartments or develops a plot for sale,
(ii) “landowner- promoter” is a promoter who transfers the land or development rights or FSI to a developer- promoter for construction of apartments and receives constructed apartments against such transferred rights and sells such apartments to his buyers independently.

Provided also that eighty percent of value of input and input services, [other than services by way of grant of development rights, long term lease of land (against upfront payment in the form of premium, salami, development charges etc.) or FSI (including additional FSI), electricity, high speed diesel, motor spirit, natural gas], used in supplying the service shall be received from registered supplier only;
Provided also that inputs and input services on which tax is paid on reverse charge basis shall be deemed to have been purchased from registered person;
Provided also that where value of input and input services received from registered suppliers during the financial year (or part of the financial year till the date of issuance of completion certificate or first occupation of the project, whichever is earlier) falls short of the said threshold of 80 per cent., tax shall be paid by the promoter on value of input and input services comprising such shortfall at the rate of eighteen percent on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017) shall apply to him as if he is the person liable for paying the tax in relation to the supply of such goods or services or both;
Provided also that notwithstanding anything contained herein above, where cement is received from an unregistered person, the promoter shall pay tax on supply of such cement at the applicable rates on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017), shall apply to him as if he is the person liable for paying the tax in relation to such supply of cement; (Please refer to the illustrations in annexure III)

Explanation. -
1. The promoter shall maintain project wise account of inward supplies from registered and unregistered supplier and calculate tax payments on the shortfall at the end of the financial year and shall submit the same in the prescribed form electronically on the common portal by end of the quarter following the financial year. The tax liability on the shortfall of inward supplies from unregistered person so determined shall be added to his output tax liability in the month not later than the month of June following the end of the financial year.
2. Notwithstanding anything contained in Explanation 1 above, tax on cement received from unregistered person shall be paid in the month in which cement is received.
3. Input Tax Credit not availed shall be reported every month by reporting the same as ineligible credit in GSTR-3B [Row No. 4 (D)(2)].

(ie) Construction of an apartment in an ongoing project under any of the schemes specified in sub-item (b), sub-item (c), sub-item (d), sub-item (da) and sub-item (db) of item (iv); sub-item (b), sub-item (c), sub-item (d) and sub-item (da) of item (v); and sub-item (c) of item (vi), against serial number 3 of the Table, in respect of which the promoter has exercised option to pay central tax on construction of apartments at the rates as specified for this item.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that in case of ongoing project, the registered person shall exercise one time option in the Form at Annexure IV to pay central tax on construction of apartments in a project at the rates as specified for item (ie) or (if), as the case may be, by the 20th of May, 2019;
Provided also that where the option is not exercised in Form at annexure IV by the 20th of May, 2019, option to pay tax at the rates as applicable to item (i) or (ia) or (ib) or (ic) or (id) above, as the case may be, shall be deemed to have been exercised;
Provided also that invoices for supply of the service can be issued during the period from 1st April 2019 to 20th May 2019 before exercising the option, but such invoices shall be in accordance with the option to be exercised.;

(if) Construction of a complex, building, civil structure or a part thereof, including,-
(i) commercial apartments (shops, offices, godowns etc.) by a promoter in a REP other than RREP,
(ii) residential apartments in an ongoing project, other than affordable residential apartments, in respect of which the promoter has exercised option to pay central tax on construction of apartments at the rates as specified for this item in the manner prescribed herein, but excluding supply by way of services specified at items (i), (ia), (ib), (ic), (id) and (ie) above intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.

Explanation. -For the removal of doubt, it is hereby clarified that, supply by way of services specified at items (i), (ia), (ib), (ic), (id) and (ie) in column (3) shall attract central tax prescribed against them in column (4) subject to conditions specified against them in column (5) and shall not be levied at the rate as specified under this entry.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that in case of ongoing project, the registered person shall exercise one time option in the Form at Annexure IV to pay central tax on construction of apartments in a project at the rates as specified for item (ie) or (if), as the case may be, by the 20th of May, 2019;
Provided also that where the option is not exercised in Form at annexure IV by the 20th of May, 2019, option to pay tax at the rates as applicable to item (i) or (ia) or (ib) or (ic) or (id) above, as the case may be, shall be deemed to have been exercised;
Provided also that invoices for supply of the service can be issued during the period from 1st April 2019 to 20th May 2019 before exercising the option, but such invoices shall be in accordance with the option to be exercised.;

(i) Construction of affordable residential apartments by a promoter in a Residential Real Estate Project (herein after referred to as RREP) which commences on or after 1st April, 2019 or in an ongoing RREP in respect of which the promoter has not exercised option to pay central tax on construction of apartments at the rates as specified for item (ie) or (if) below, as the case may be, in the manner prescribed therein, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
(Provisions of paragraph 2 of this notification shall apply for valuation of this service)

Provided that the central tax at the rate specified in column (4) shall be paid in cash, that is, by debiting the electronic cash ledger only; Provided also that credit of input tax charged on goods and services used in supplying the service hasnot been taken except to the extent as prescribed in Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP;

Provided also that the registered person shall pay, by debit in the electronic credit ledger or electronic cash ledger, an amount equivalent to the input tax credit attributable to construction in a project, time of supply of which is on or after 1st April, 2019, which shall be calculated in the manner as prescribed in the Annexure I in the case of REP other than RREP and in Annexure II in the case of RREP; Provided also that where a registered person (landowner- promoter) who transfers development right or FSI (including additional FSI) to a promoter (developer- promoter) against consideration, wholly or partly, in the form of construction of apartments,-
(i) the developer- promoter shall pay tax on supply of construction of apartments to the landowner- promoter, and
(ii) such landowner – promoter shall be eligible for credit of taxes charged from him by the developer promoter towards the supply of construction of apartments by developer- promoter to him, provided the landowner- promoter further supplies such apartments to his buyers before issuance of completion certificate or first occupation, whichever is earlier, and pays tax on the same which is not less than the amount of tax charged from him on construction of such apartments by the developer- promoter.

Explanation. -
(i) “developer- promoter” is a promoter who constructs or converts a building into apartments or develops a plot for sale,
(ii) “landowner- promoter” is a promoter who transfers the land or development rights or FSI to a developer- promoter for construction of apartments and receives constructed apartments against such transferred rights and sells such apartments to his buyers independently.

Provided also that eighty percent of value of input and input services, [other than services by way of grant of development rights, long term lease of land (against upfront payment in the form of premium, salami, development charges etc.) or FSI (including additional FSI), electricity, high speed diesel, motor spirit, natural gas], used in supplying the service shall be received from registered supplier only;
Provided also that inputs and input services on which tax is paid on reverse charge basis shall be deemed to have been purchased from registered person;
Provided also that where value of input and input services received from registered suppliers during the financial year (or part of the financial year till the date of issuance of completion certificate or first occupation of the project, whichever is earlier) falls short of the said threshold of 80 per cent., tax shall be paid by the promoter on value of input and input services comprising such shortfall at the rate of eighteen percent on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017) shall apply to him as if he is the person liable for paying the tax in relation to the supply of such goods or services or both;
Provided also that notwithstanding anything contained herein above, where cement is received from an unregistered person, the promoter shall pay tax on supply of such cement at the applicable rates on reverse charge basis and all the provisions of the Central Goods and Services Tax Act, 2017 (12 of 2017), shall apply to him as if he is the person liable for paying the tax in relation to such supply of cement; (Please refer to the illustrations in annexure III)

Explanation. -
1. The promoter shall maintain project wise account of inward supplies from registered and unregistered supplier and calculate tax payments on the shortfall at the end of the financial year and shall submit the same in the prescribed form electronically on the common portal by end of the quarter following the financial year. The tax liability on the shortfall of inward supplies from unregistered person so determined shall be added to his output tax liability in the month not later than the month of June following the end of the financial year.
2. Notwithstanding anything contained in Explanation 1 above, tax on cement received from unregistered person shall be paid in the month in which cement is received.
3. Input Tax Credit not availed shall be reported every month by reporting the same as ineligible credit in GSTR-3B [Row No. 4 (D)(2)].

(iii) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and ServicesTax Act, 2017, supplied to the Central Government, State Government, Union territory, a local authority, a Governmental Authority or a Government Entity by way of construction, erection, commissioning, installation, completion, fitting out, repair, maintenance, renovation, or alteration of, -
(a) a historical monument, archaeological site or remains of national importance, archaeological excavation, or antiquity specified under the Ancient Monuments and Archaeological Sites and Remains Act, 1958 (24 of 1958);
(b) canal, dam or other irrigation works;
(c) pipeline, conduit or plant for (i) water supply (ii) water treatment, or (iii) sewerage treatment or disposal.

Provided that where the services are supplied to a Government Entity, they should have been procured by the said entity in relation to a work entrusted to it by the Central Government, State Government, Union territory or local authority, as the case may be;

(iv) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017, other than that covered by items (i), (ia), (ib), (ic), (id), (ie) and (if) above, supplied by way of construction, erection, commissioning, installation, completion, fitting out, repair, maintenance, renovation, or alteration of,-
(a) a road, bridge, tunnel, or terminal for road transportation for use by general public;
(b) a civil structure or any other original works pertaining to a scheme under Jawaharlal Nehru National Urban Renewal Mission or Rajiv Awaas Yojana;
(c) a civil structure or any other original works pertaining to the “in-situ redevelopment of existing slums using land as a resource, under the Housing for All (Urban) Mission/ Pradhan Mantri Awas Yojana (Urban)
(d) a civil structure or any other original works pertaining to the “Beneficiary led individual house construction / enhancement” under the Housing for All (Urban) Mission/Pradhan Mantri AwasYojana;
(da) a civil structure or any other original works pertaining to the “Economically Weaker Section (EWS) houses” constructed under the Affordable Housing in partnership by State or Union territory or local authority or urban development authority under the Housing for All (Urban) Mission/ Pradhan Mantri Awas Yojana (Urban);
(db) a civil structure or any other original works pertaining to the “houses constructed or acquired under the Credit Linked Subsidy Scheme for Economically Weaker Section (EWS)/ Lower Income Group (LIG)/ Middle Income Group-1 (MlG-1)/ Middle Income Group-2 (MlG-2)” under the Housing for All (Urban) Mission/ Pradhan Mantri Awas Yojana (Urban);
(e) a pollution control or effluent treatment plant, except located as a part of a factory; or
(f) a structure meant for funeral, burial or cremation of deceased
(g) a building owned by an entity registered under section 12AA of the Income Tax Act, 1961 (43 of 1961), which is used for carrying out the activities of providing, centralised cooking or distribution, for mid-day meals under the mid-day meal scheme sponsored by the Central Government, State Government, Union territory or local authorities.

-

(v) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017, other than that covered by items (i), (ia), (ib), (ic), (id), (ie) and (if) above, supplied by way of construction, erection, commissioning, or installation of original works pertaining to,-
(a) railways, including monorail and metro;
(b) a single residential unit otherwise than as a part of a residential complex;
(c) low-cost houses up to a carpet area of 60 square metres per house in a housing project approved by competent authority empowered under the 'Scheme of Affordable Housing in Partnership' framed by the Ministry of Housing and Urban Poverty Alleviation, Government of India;
(d) low cost houses up to a carpet area of 60 square metres per house in a housing project approved by the competent authority under- (1) the “Affordable Housing in Partnership” component of the Housing for All (Urban) Mission/Pradhan Mantri Awas Yojana; (2) any housing scheme of a State Government;
(da) low-cost houses up to a carpet area of 60 square metres per house in an affordable housing project which has been given infrastructure status vide notification of Government of India, in Ministry of Finance, Department of Economic Affairs vide F. No. 13/6/2009-INF, dated the 30th March,2017;
(e) post-harvest storage infrastructure for agricultural produce including a cold storage for such purposes; or
(f) mechanised food grain handling system, machinery or equipment for units processing agricultural produce as food stuff excluding alcoholic beverages.,-

-

(va) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017, other than that covered by items (i), (ia), (ib), (ic), (id), (ie) and (if) above, supplied by way of construction, erection, commissioning, installation, completion, fitting out, repair, maintenance, renovation, or alteration of affordable residential apartments covered by sub- clause (a) of clause (xvi) of paragraph 4 below, in a project which commences on or after 1st April, 2019, or in an ongoing project in respect of which the promoter has not exercised option to pay central tax on construction of apartments at the rates as specified for item (ie) or (if), as the case may be, in the manner prescribed therein,

Provided that carpet area of the affordable residential apartments as specified in the entry in column (3) relating to this item, is not less than 50 per cent. of the total carpet area of all the apartments in the project;
Provided also that for the purpose of determining whether the apartments at the time of supply of the service are affordable residential apartments covered by sub- clause (a) of clause (xvi) of paragraph 4 below or not, value of the apartments shall be the value of similar apartments booked nearest to the date of signing of the contract for supply of the service specified in the entry in column (3) relating to this item; Provided also that in case it finally turns out that the carpet area of the affordable residential apartments booked or sold before or after completion, for which gross amount actually charged was forty five lakhs rupees or less and the actual carpet area was within the limits prescribed in sub- clause (a) of clause (xvi) of paragraph 4 below, was less than 50 per cent. of the total carpet area of all the apartments in the project, the recipient of the service, that is, the promoter shall be liable to pay such amount of tax on reverse charge basis as is equal to the difference between the tax payable on the service at the applicable rate but for the rate prescribed herein and the tax actually paid at the rate prescribed herein;

(vi) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017, other than that covered by items (i), (ia), (ib), (ic), (id), (ie) and (if) above, provided to the Central Government, State Government, Union Territory, a local authority, a Governmental Authority or a Government Entity by way of construction, erection, commissioning, installation, completion, fitting out, repair, maintenance, renovation, or alteration of –
(a) a civil structure or any other original works meant predominantly for use other than for commerce, industry, or any other business or profession;
(b) a structure meant predominantly for use as (i) an educational, (ii)a clinical, or(iii) an art or cultural establishment; or
(c) a residential complex predominantly meant for self-use or the use of their employees or other persons specified in paragraph 3 of the Schedule III of the Central Goods and Services Tax Act, 2017.
Explanation. - For the purposes of this item, the term ‘business’ shall not include any activity or transaction undertaken by the Central Government, a State Government or any local authority in which they are engaged as public authorities.

Provided that where the services are supplied to a Government Entity, they should have been procured by the said entity in relation to a work entrusted to it by the Central Government, State Government, Union territory or local authority, as the case may be

(vii) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017, involving predominantly earth work (that is, constituting more than 75per cent. of the value of the works contract) provided to the Central Government, State Government, Union territory, local authority, a Governmental Authority or a Government Entity.

Provided that where the services are supplied to a Government Entity, they should have been procured by the said entity in relation to a work entrusted to it by the Central Government, State Government, Union territory or local authority, as the case may be

Electricity, gas, water and other distribution services.

-

(viii) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017 and associated services, in respect of offshore works contract relating to oil and gas exploration and production (E&P) in the offshore area beyond 12 nautical miles from the nearest point of the appropriate base line.

-

(ix) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017 provided by a sub-contractor to the main contractor providing services specified in item (iii) or item (vi) above to the Central Government, State Government, Union territory, a local authority, a Governmental Authority or a Government Entity.

Provided that where the services are supplied to a Government Entity, they should have been procured by the said entity in relation to a work entrusted to it by the Central Government, State Government, Union territory or local authority, as the case may be.

(x) Composite supply of works contract as defined in clause (119) of section 2 of the Central Goods and Services Tax Act, 2017 provided by a sub-contractor to the main contractor providing services specified in item (vii) above to the Central Government, State Government, Union territory, a local authority, a Governmental Authority or a Government Entity.

Provided that where the services are supplied to a Government Entity, they should have been procured by the said entity in relation to a work entrusted to it by the Central Government, State Government, Union territory or local authority, as the case may be.

(xi) Services by way of house-keeping, such as plumbing, carpentering, etc. where the person supplying such service through electronic commerce operator is not liable for registration under sub-section (1) of section 22 of the Central Goods and Services Tax Act, 2017.

Provided that credit of input tax charged on goods and services has not been taken
[Please refer to Explanation no. (iv)].

(xii) Construction services other than (i), (ia), (ib), (ic), (id), (ie), (if), (iii), (iv), (v), (va), (vi), (vii), (viii), (ix), (x) and (xi) above.
Explanation. - For the removal of doubt, it is hereby clarified that, supply by way of services specified at items (i), (ia), (ib), (ic), (id), (ie) and (if) in column (3) shall attract central tax prescribed against them in column (4) subject to conditions specified against them in column (5) and shall not be levied at the rate as specified under this entry.

-

Services in wholesale trade.
Explanation-This service does not include sale or purchase of goods but includes:
– Services of commission agents, commodity brokers, and auctioneers and all other traders who negotiate whole sale commercial transactions between buyers and sellers, for a fee or commission
– Services of electronic whole sale agents and brokers,
– Services of whole sale auctioning houses.

-

Services in retail trade.
Explanation- This service does not include sale or purchase of goods.

-

“(i) Supply of „hotel accommodation‟ having value of supply of a unit of accommodation above one thousand rupees but less than or equal to seven thousand five hundred rupees per unit per day or equivalent.

(ii) Supply of „restaurant service‟ other than at „specified premises‟

Provided that credit of input tax charged on goods and services used in supplying the service has not been taken [Please refer to Explanation no. (iv)]

(iii) Supply of goods, being food or any other article for human consumption or any drink, by the Indian Railways or Indian Railways Catering and Tourism Corporation Ltd. or their licensees, whether in trains or at platforms.

Provided that credit of input tax charged on goods and services used in supplying the service has not been taken [Please refer to Explanation no. (iv)]

(iv) Supply of „outdoor catering‟, at premises other than „specified premises‟ provided by any person other than-
(a) suppliers providing „hotel accommodation‟ at „specified premises‟, or
(b) suppliers located in „specified premises‟.

Provided that credit of input tax charged on goods and services used in supplying the service has not been taken [Please refer to Explanation (iv)]

(v) Composite supply of „outdoor catering‟ together with renting of premises (including hotel, convention center, club, pandal, shamiana or any other place, specially arranged for organising a function) at premises other than „specified premises‟ provided by any person other than-
(a) suppliers providing „hotel accommodation‟ at „specified premises‟, or
(b) suppliers located in „specified premises‟.

Provided that credit of input tax charged on goods and services used in supplying the service has not been taken [Please refer to Explanation (iv)]

(vi) Accommodation, food and beverage services other than (i) to (v) above

Explanation:
(a) For the removal of doubt, it is hereby clarified that, supplies covered by items (ii), (iii), (iv) and (v) in column (3) shall attract central tax prescribed against them in column (4) subject to conditions specified against them in column (5), which is a mandatory rate and shall not be levied at the rate as specified under this entry.
(b) This entry covers supply of "restaurant service" at "specified premises"
(c) This entry covers supply of "hotel accommodation" having value of supply of a unit of accommodation above seven thousand five hundred rupees per unit per day or equivalent.
(d) This entry covers supply of "outdoor catering", provided by suppliers providing "hotel accommodation" at "specified premises", or suppliers located in "specified premises".
(e) This entry covers composite supply of "outdoor catering" together with renting of premises (including hotel, convention center, club, pandal, shamiana or any other place, specially arranged for organising a function) provided by suppliers providing "hotel accommodation" at "specified premises", or suppliers located in „specified premises

(i) Transport of passengers, with or without accompanied belongings, by rail in first class or air conditioned coach.

Provided that credit of input tax charged in respect of goods used in supplying the service is not utilised for paying central tax or integrated tax on the supply of the service

(ii) Transport of passengers, with or without accompanied belongings by-
(a) air conditioned contract carriage other than motorcab;
(b) air conditioned stage carriage;
(c) radio taxi.
Explanation.-
(a) "contract carriage" has the meaning assigned to it in clause (7) of section 2 of the Motor Vehicles Act, 1988 (59 of 1988);
(b) "stage carriage" has the meaning assigned to it in clause (40) of section 2 of the Motor Vehicles Act, 1988 (59 of 1988) ;
(c) "radio taxi" means a taxi including a radio cab, by whatever name called, which is in two-way radio communication with a central control office and is enabled for tracking using Global Positioning System (GPS) or General Packet Radio Service (GPRS).

Provided that credit of input tax charged on goods and services usedin supplying the service has not been taken
[Please refer to Explanation no. (iv)]

(iii) Transport of passengers, with or without accompanied belongings, by air in economy class.

Provided that credit of input tax charged on goods used in supplying the service has not been taken
[Please refer to Explanation no. (iv)]

(iv) Transport of passengers, with or without accompanied belongings, by air, embarking from or terminating in a Regional Connectivity Scheme Airport, as notified by the Ministry of Civil Aviation.

Provided that credit of input tax charged on goods used in supplying the service has not been taken
[Please refer to Explanation no. (iv)]

(iva) Transportation of passengers, with or without accompanied baggage, by air, by non-scheduled air transport service or charter operations, engaged by specified organisations in respect of religious pilgrimage facilitated by the Government of India, under bilateral arrangement.

Provided that credit of input tax charged on goods used in supplying the service has not been taken
[Please refer to clause (iv) of paragraph 4 relating to Explanation]

(v) Transport of passengers by air, with or without accompanied belongings, in other than economy class.

-

(vi) Transport of passengers by any motor vehicle designed to carry passengers where the cost of fuel is included in the consideration charged from the service recipient.

Provided that credit of input tax charged on goods and services used in supplying the service, other than the input tax credit of input service in the same line of business (i.e. service procured from another service provider of transporting passengers in a motor vehicle or renting of a motor vehicle), has not been taken. [Please refer to Explanation no. (iv)]

(vi) Transport of passengers by any motor vehicle designed to carry passengers where the cost of fuel is included in the consideration charged from the service recipient.

-

(vii) Passenger transport services other than (i), (ii) (iii), (iv), (iva), (v) and (vi) above.

-

(i) Transport of goods by rail (other than services specified at item no. (iv)).

Provided that credit of input tax charged in respect of goods in supplying the service is not utilised for paying central tax or integrated tax on the supply of the service

(ii) Transport of goods in a vessel.

Provided that credit of input tax charged on goods (other than on ships, vessels including bulk carriers and tankers) used in supplying the service has not been taken
[Please refer to Explanation no. (iv)]

(iii) Services of goods transport agency (GTA) in relation to transportation of goods (including used household goods for personal use).

Explanation.- "goods transport agency" means any person who provides service in relation to transport of goods by road and issues consignment note, by whatever name called.

Provided that credit of input tax charged on goods and services used in supplying the service has not been taken

[Please refer to Explanation no. (iv)]

(iii) Services of goods transport agency (GTA) in relation to transportation of goods (including used household goods for personal use).

Explanation.- "goods transport agency" means any person who provides service in relation to transport of goods by road and issues consignment note, by whatever name called.

Provided that the goods transport agency opting to pay central tax @ 6% under this entry shall, thenceforth, be liable to pay central tax @ 6% on all the services of GTA supplied by it.

(iv) Transport of goods in containers by rail by any person other than Indian Railways.

-

(v) Transportation of natural gas, petroleum crude, motor spirit (commonly known as petrol), high speed diesel or aviation turbine fuel through pipeline

Provided that credit of input tax charged on goods and services used in supplying the service has not been taken [Please refer to Explanation no. (iv)]

(vi) Multimodal transportation of goods.
Explanation.-
(a) “multimodal transportation” means carriage of goods, by at least two different modes of transport from the place of acceptance of goods to the place of delivery of goods by a multimodal transporter;
(b) “mode of transport” means carriage of goods by road, air, rail, inland waterways or sea;
(c) “multimodal transporter” means a person who,- (A) enters into a contract under which he undertakes to perform multimodal transportation against freight; and (B) acts as principal, and not as an agent either of the consignor, or consignee or of the carrier participating in the multimodal transportation and who assumes responsibility for the performance of the said contract.

Explanation 2.-
Nothing contained in this item shall apply to supply of a service other than by way of transport of goods from a place in India to another place in India.

-

(vii) Goods transport services other than (i), (ii), (iii), (iv), (v) and (vi) above

-

(i)Renting of any motor vehicle designed to carry passengers where the cost of fuel is included in the consideration charged from the service recipient.

Provided that credit of input tax charged on goods and services used in supplying the service, other than the input tax credit of input service in the same line of business (i.e. service procured from another service provider of transporting passengers in a motor vehicle or renting of a motor vehicle) has not been taken. [Please refer to Explanation no. (iv)]

(i)Renting of any motor vehicle designed to carry passengers where the cost of fuel is included in the consideration charged from the service recipient.

-

(ii) Time charter of vessels for transport of goods.

Provided that credit of input tax charged on goods (other than on ships, vessels including bulk carriers and tankers) has not been taken

(iii) Rental services of transport vehicles with operators, other than (i) and (ii) above.

-

(i) Services of goods transport agency (GTA) in relation to transportation of goods (including used household goods for personal use).
Explanation.- “goods transport agency” means any person who provides service in relation to transport of goods by road and issues consignment note, by whatever name called.

Provided that credit of input tax charged on goods and services used in supplying the service has not been taken
[Please refer to Explanation no. (iv)]

(i) Services of goods transport agency (GTA) in relation to transportation of goods (including used household goods for personal use).
Explanation.- "goods transport agency" means any person who provides service in relation to transport of goods by road and issues consignment note, by whatever name called.

Provided that the goods transport agency opting to pay central tax @ 6% under this entry shall, thenceforth, be liable to pay central tax @ 6% on all the services of GTA supplied by it.

(ii) Supporting services in transport other than (i) above.

-

Postal and courier services.

-

(i) Services provided by a foreman of a chit fund in relation to chit.
Explanation.-

(a) "chit" means a transaction whether called chit, chit fund, chitty, kuri, or by whatever name by or under which a person enters into an agreement with a specified number of persons that every one of them shall subscribe a certain sum of money (or a certain quantity of grain instead) by way of periodical instalments over a definite period and that each subscriber shall, in his turn, as determined by lot or by auction or by tender or in such other manner as may be specified in the chit agreement, be entitled to a prize amount;
(b)“foreman of a chit fund” shall have the same meaning as is assigned to the expression “foreman” in clause (j) of section 2 of the Chit Funds Act, 1982 (40 of 1982).

Provided that credit of input tax charged on goods used in supplying the service has not been taken
[Please refer to Explanation no. (iv)]

(ii) Transfer of the right to use any goods for any purpose (whether or not for a specified period) for cash, deferred payment or other valuable consideration.

-

(iii) Any transfer of right in goods or of undivided share in goods without the transfer of title thereof.

-

(v) Leasing of motor vehicles purchased and leased prior to 1st July 2017;

-

(vi) Service of third party insurance of “goods carriage

-

(vii) Financial and related services other than (i), (ii), (iii), (v) and (vi) above.

-

(i) Services by the Central Government, State Government, Union territory or local authority to governmental authority or government entity, by way of lease of land.

-

(ii) Supply of land or undivided share of land by way of lease or sub lease where such supply is a part of composite supply of construction of flats, etc. specified in the entry in column (3), against serial number 3, at item (i); (i) (ia), (ib), (ic), (id), (ie) and (if).
Provided that nothing contained in this entry shall apply to an amount charged for such lease and sub-lease in excess of one third of the total amount charged for the said composite supply. Total amount shall have the same meaning for the purpose of this proviso as given in paragraph 2 of this notification.

-

(iii) Real estate services other than (i) and (ii) above.

-

(i) Temporary or permanent transfer or permitting the use or enjoyment of Intellectual Property (IP) right in respect of goods other than Information Technology software.

-

(ii) Temporary or permanent transfer or permitting the use or enjoyment of Intellectual Property (IP) right in respect of Information Technology software.
[Please refer to Explanation no. (v)]

-

(iii) Transfer of the right to use any goods for any purpose (whether or not for a specified period) for cash, deferred payment or other valuable consideration.

-

(iv) Any transfer of right in goods or of undivided share in goods without the transfer of title thereof.

-

(vi) Leasing of motor vehicles purchased and leased prior to 1stJuly 2017;

-

(viia) Leasing or renting of goods

(viii) Leasing or rental services, without operator, other than (i), (ii), (iii), (iv), (vi), and (viia) above.

-

Research and development services.

-

Legal and accounting services.

-

(i) Selling of space for advertisement in print media.

-

(ia) Other professional, technical and business services relating to exploration, mining or drilling of petroleum crude or natural gas or both

-

(ii) Other professional, technical and business services other than (i) and (ia) above and serial number 38 below.

-

(i) Supply consisting only of e-book.
Explanation.- For the purposes of this notification, “ebooks” means an electronic version of a printed book (falling under tariff item 4901 in the First Schedule to the Customs Tariff Act, 1975 (51 of 1975)) supplied online which can be read on a computer or a hand held device.

-

(ii) Telecommunications, broadcasting and information supply services other than (i) above.

-

(iv) Manufacturing services on physical inputs (goods) owned by others, other than (i), (ia), (ib), (ic), (id), (ii), (iia) and (iii) above.

-

(i) Supply of tour operators services.
Explanation.- "tour operator" means any person engaged in the business of planning, scheduling, organizing, arranging tours (which may include arrangements for accommodation, sightseeing or other similar services) by any mode of transport, and includes any person engaged in the business of operating tours.

1. Provided that credit of input tax charged on goods and services used in supplying the service, other than the input tax credit of input service in the same line of business (i.e. tour operator service procured from another tour operator) has not been taken
[Please refer to Explanation no. (iv)]
2. The bill issued for supply of this service indicates that it is inclusive of charges of accommodation and transportation required for such a tour and the amount charged in the bill is the gross amount charged for such a tour including the charges of accommodation and transportation required for such a tour.

(ii) Services by way of house-keeping, such as plumbing, carpentering, etc. where the person supplying such service through electronic commerce operator is not liable for registration under sub-section (1) of section 22 of the Central Goods and Services Tax Act, 2017.

Provided that credit of input tax charged on goods and services has not been taken

[Please refer to Explanation no. (iv)].

(iii) Support services other than (i) and (ii) above.

-

(i) Support services to agriculture, forestry, fishing, animal husbandry.
Explanation. – "Support services to agriculture, forestry, fishing, animal husbandry" mean -
(i) Services relating to cultivation of plants and rearing of all life forms of animals, except the rearing of horses, for food, fibre, fuel, raw material or other similar products or agricultural produce by way of—
(a) agricultural operations directly related to production of any agricultural produce including cultivation, harvesting, threshing, plant protection or testing;
(b) supply of farm labour;
(c) processes carried out at an agricultural farm including tending, pruning, cutting, harvesting, drying, cleaning, trimming, sun drying, fumigating, curing, sorting, grading, cooling or bulk packaging and such like operations which do not alter the essential characteristics of agricultural produce but make it only marketable for the primary market;
(d) renting or leasing of agro machinery or vacant land with or without a structure incidental to its use;
(e) loading, unloading, packing, storage or warehousing of agricultural produce;
(f) agricultural extension services;
(g) services by any Agricultural Produce Marketing Committee or Board or services provided by a commission agent for sale or purchase of agricultural produce.
(h) services by way of fumigation in a warehouse of agricultural produce.
(ii) Services by way of pre-conditioning, pre-cooling, ripening, waxing, retail packing, labelling of fruits and vegetables which do not change or alter the essential characteristics of the said fruits or vegetables.
(iii) Carrying out an intermediate production process as job work in relation to cultivation of plants and rearing of all life forms of animals, except the rearing of horses, for food, fibre, fuel, raw material or other similar products or agricultural produce.

-

(ii) Support services to exploration, mining or drilling of petroleum crude or natural gas or both.

-

(iii) Support services to mining, electricity, gas and water distribution other than (ii) above.

-

(i) Services by way of house-keeping, such as plumbing, carpentering, etc. where the person supplying such service through electronic commerce operator is not liable for registration under sub-section (1) of section 22 of the Central Goods and Services Tax Act, 2017.

Provided that credit of input tax charged on goods and services has not been taken

[Please refer to Explanation no. (iv)].

(ia)Maintenance, repair or overhaul services in respect of aircrafts, aircraft engines and other aircraft components or parts.

-

(ii) Maintenance, repair and installation (except construction) services, other than (i) and (ia) above and serial number 38 below.

-

(i) Services by way of job work in relation to-
(a) Printing of newspapers;
(b) Textiles and textile products falling under Chapter 50 to 63 in the First Schedule to the Customs Tariff Act, 1975 (51of 1975);
(c) all products, other than diamonds, falling under Chapter 71 in the First Schedule to the Customs Tariff Act, 1975 (51of 1975);
(d) Printing of books (including Braille books), journals and periodicals;
(da) printing of all goods falling under Chapter 48 or 49, which attract CGST @ 2.5per cent. or Nil
(e) Processing of hides, skins and leather falling under Chapter 41 in the First Schedule to the Customs Tariff Act, 1975 (51of 1975).
(ea) manufacture of leather goods or foot wear falling under Chapter 42 or 64 in the First Schedule to the Customs Tariff Act, 1975 (51of 1975) respectively;
(f) all food and food products falling under Chapters 1 to 22 in the First Schedule to the Customs Tariff Act, 1975 (51 of 1975);
(g) all products falling under Chapter 23 in the First Schedule to the Customs Tariff Act, 1975 (51of 1975), except dog and cat food put up for retail sale falling under tariff item 23091000 of the said Chapter;
(h) manufacture of clay bricks falling under tariff item 69010010 in the First Schedule to the Customs Tariff Act, 1975 (51of 1975);
(i) manufacture of handicraft goods.
Explanation.- The expression “handicraft goods” shall have the same meaning as assigned to it in the notification No. 32/2017 -Central Tax, dated the 15th September, 2017 published in the Gazette of India, Extraordinary, Part II, Section 3, Sub-section (i), vide number G.S.R. 1158 (E), dated the 15th September, 2017 as amended from time to time.

-

(ia)Services by way of job work in relation to- (a) manufacture of umbrella; (b) printing of all goods falling under Chapter 48 or 49, which attract CGST @ 6per cent

-

(ib) Services by way of job work in relation to diamonds falling under chapter 71 in the First Schedule to the Customs Tariff Act, 1975 (51of 1975);

-

(ic) Services by way of job work in relation to bus body building;

Explanation- For the purposes of this entry, the term “bus body building” shall include building of body on chassis of any vehicle falling under chapter 87 in the First Schedule to the Customs Tariff Act, 1975.”

(id) Services by way of job work other than (i), (ia), (ib) and (ic) above;

-

(ii) Services by way of any treatment or process on goods belonging to another person, in relation to-
(a) printing of newspapers;
(b) printing of books (including Braille books), journals and periodicals
(c) printing of all goods falling under Chapter 48 or 49, which attract CGST @ 2.5 per cent. or Nil.

-

(iia) Services by way of any treatment or process on goods belonging to another person, in relation to printing of all goods falling under Chapter 48 or 49, which attract CGST @ 6per cent.

-

(iii) Tailoring services.

-

(i) Services by way of printing of all goods falling under Chapter 48 or 49 including newspapers, books (including Braille books), journals and periodicals], which attract CGST @ 6 per cent. or 2.5per cent. or Nil, where only content is supplied by the publisher and the physical inputs including paper used for printing belong to the printer.

-

(ii) Other manufacturing services; publishing, printing and reproduction services; materials recovery services, other than (i) above.

-

Public administration and other services provided to the community as a whole; compulsory social security services.

-

Education services.

-

Human health and social care services.

-

(i)Services by way of treatment of effluents by a Common Effluent Treatment Plant.

-

(ii) Sewage and waste collection, treatment and disposal and other environmental protection services other than (i) above.

-

Services of membership organisations.

-

(i) Services by way of admission or access to circus, Indian classical dance including folk dance, theatrical performance, drama or planetarium.

-

(ii) Services by way of admission to exhibition of cinematograph films where price of admission ticket is one hundred rupees or less.

-

(iia) Services by way of admission to exhibition of cinematograph films where price of admission ticket is above one hundred rupees.

-

(iii) Services by way of admission to amusement parks including theme parks, water parks, joy rides, merry-go rounds, go-carting and ballet.

-

(iiia) Services by way of admission to entertainment events or access to amusement facilities including casinos, race club, any sporting event such as Indian Premier League and the like.

-

(iv) Services provided by a race club by way of totalisator or a license to bookmaker in such club.

-

(v) Gambling.

-

(vi) Recreational, cultural and sporting services other than (i), (ii), (iia), (iii), (iiia), (iv) and (v) above.

-

Other services (washing, cleaning and dyeing services; beauty and physical well-being services; and other miscellaneous services including services nowhere else classified).

-

Domestic services.

-

Services provided by extraterritorial organisations and bodies.

-

Service by way of construction or engineering or installation or other technical services, provided in relation of setting up of following, -
(a) Bio-gas plant
(b) Solar power based devices
(c) Solar power generating system
(d) Wind mills, Wind Operated Electricity Generator (WOEG)
(e) Waste to energy plants / devices
(f) Ocean waves/tidal waves energy devices/plants

Explanation:- This entry shall be read in conjunction with serial number 234 of Schedule I of the notification No. 1/2017-Central Tax (Rate), published in the Gazette of India, Extraordinary, Part II, Section 3, Sub-section (i) dated 28th June, 2017 vide GSR number 673(E) dated 28th June, 2017.

-

Service by way of construction or engineering or installation or other technical services, provided in relation of setting up of following, -
(a) Bio-gas plant
(b) Solar power based devices
(c) Solar power generating system
(d) Wind mills, Wind Operated Electricity Generator (WOEG)
(e) Waste to energy plants / devices
(f) Ocean waves/tidal waves energy devices/plants

Explanation:- This entry shall be read in conjunction with serial number 234 of Schedule I of the notification No. 1/2017-Central Tax (Rate), published in the Gazette of India, Extraordinary, Part II, Section 3, Sub-section (i) dated 28th June, 2017 vide GSR number 673(E) dated 28th June, 2017.

-

Service by way of construction or engineering or installation or other technical services, provided in relation of setting up of following, -
(a) Bio-gas plant
(b) Solar power based devices
(c) Solar power generating system
(d) Wind mills, Wind Operated Electricity Generator (WOEG)
(e) Waste to energy plants / devices
(f) Ocean waves/tidal waves energy devices/plants

Explanation:- This entry shall be read in conjunction with serial number 234 of Schedule I of the notification No. 1/2017-Central Tax (Rate), published in the Gazette of India, Extraordinary, Part II, Section 3, Sub-section (i) dated 28th June, 2017 vide GSR number 673(E) dated 28th June, 2017.

-

Services provided by way of pure labour contracts of construction, erection, commissioning, installation, completion, fitting out, repair, maintenance, renovation, or alteration of a civil structure or any other original works pertaining to the beneficiary-led individual house construction or enhancement under the Housing for All (Urban) Mission or Pradhan MantriAwasYojana.

Services supplied by electricity distribution utilities by way of construction, erection, commissioning, or installation of infrastructure for extending electricity distribution network upto the tube well of the farmer or agriculturalist for agricultural use.

Service provided by Fair Price Shops to Central Government, State Government or Union territory by way of sale of food grains, kerosene, sugar, edible oil, etc. under Public Distribution System against consideration in the form of commission or margin.

Service provided by Fair Price Shops to Central Government, State Government or Union territory by way of sale of food grains, kerosene, sugar, edible oil, etc. under Public Distribution System against consideration in the form of commission or margin.

Services by way of renting of residential dwelling for use as residence.

Services by way of renting of residential dwelling for use as residence.

Services by a person by way of-
(a) conduct of any religious ceremony;
(b) renting of precincts of a religious place meant for general public, owned or managed by an entity registered as a charitable or religious trust under section 12AA of the Income-tax Act, 1961 (hereinafter referred to as the Income-tax Act) or a trust or an institution registered under sub clause (v) of clause (23C) of section 10 of the Income-tax Act or a body or an authority covered under clause (23BBA) of section 10 of the said Income-tax Act:
Provided that nothing contained in entry (b) of this exemption shall apply to,-
(i) renting of rooms where charges are one thousand rupees or more per day;
(ii) renting of premises, community halls, kalian mandapam or open area, and the like where charges are ten thousand rupees or more per day;
(iii) renting of shops or other spaces for business or commerce where charges are ten thousand rupees or more per month.

Services by a person by way of-
(a) conduct of any religious ceremony;
(b) renting of precincts of a religious place meant for general public, owned or managed by an entity registered as a charitable or religious trust under section 12AA of the Income-tax Act, 1961 (hereinafter referred to as the Income-tax Act) or a trust or an institution registered under sub clause (v) of clause (23C) of section 10 of the Income-tax Act or a body or an authority covered under clause (23BBA) of section 10 of the said Income-tax Act:
Provided that nothing contained in entry (b) of this exemption shall apply to,-
(i) renting of rooms where charges are one thousand rupees or more per day;
(ii) renting of premises, community halls, kalian mandapam or open area, and the like where charges are ten thousand rupees or more per day;
(iii) renting of shops or other spaces for business or commerce where charges are ten thousand rupees or more per month.

Services by a person by way of-
(a) conduct of any religious ceremony;
(b) renting of precincts of a religious place meant for general public, owned or managed by an entity registered as a charitable or religious trust under section 12AA of the Income-tax Act, 1961 (hereinafter referred to as the Income-tax Act) or a trust or an institution registered under sub clause (v) of clause (23C) of section 10 of the Income-tax Act or a body or an authority covered under clause (23BBA) of section 10 of the said Income-tax Act:
Provided that nothing contained in entry (b) of this exemption shall apply to,-
(i) renting of rooms where charges are one thousand rupees or more per day;
(ii) renting of premises, community halls, kalian mandapam or open area, and the like where charges are ten thousand rupees or more per day;
(iii) renting of shops or other spaces for business or commerce where charges are ten thousand rupees or more per month.

Services by a hotel, inn, guest house, club or campsite, by whatever name called, for residential or lodging purposes, having value of supply of a unit of accommodation below or equal to one thousand rupees per day or equivalent.

Transport of passengers, with or without accompanied belongings, by –
(a) air, embarking from or terminating in an airport located in the state of Arunachal Pradesh, Assam, Manipur, Meghalaya, Mizoram, Nagaland, Sikkim, or Tripura or at Bagdogra located in West Bengal;
(b) non-airconditioned contract carriage other than radio taxi, for transportation of passengers, excluding tourism, conducted tour, charter or hire; or
(c) stage carriage other than air-conditioned stage carriage.

Services provided to the Central Government, by way of transport of passengers with or without accompanied belongings, by air, embarking from or terminating at a regional connectivity scheme airport, against consideration in the form of viability gap funding:
Provided that nothing contained in this entry shall apply on or after the expiry of a period of three years from the date of commencement of operations of the regional connectivity scheme airport as notified by the Ministry of Civil Aviation.

Service of transportation of passengers, with or without accompanied belongings, by—
(a) railways in a class other than—
(i) first class; or
(ii) an air-conditioned coach;
(b) metro, monorail or tramway;
(c) inland waterways;
(d) public transport, other than predominantly for tourism purpose, in a vessel between places located in India; and
(e) metered cabs or auto rickshaws (including e-rickshaws).

Services by way of transportation of goods-
(a) by road except the services of—
(i) a goods transportation agency;
(ii) a courier agency;
(b) by inland waterways.

Services by way of transportation of goods by an aircraft from a place outside India upto the customs station of clearance in India.

Services by way of transportation of goods by an aircraft from customs station of clearance in India to a place outside India.

Nothing contained in this serial number shall apply after the 30thday of September, 2020.

Services by way of transportation of goods by a vessel from customs station of clearance in India to a place outside India.

Nothing contained in this serial number shall apply after the 30thday of September, 2020.

Services by way of transportation by rail or a vessel from one place in India to another of the following goods –
(a) relief materials meant for victims of natural or man-made disasters, calamities, accidents or mishap;
(b) defence or military equipments;
(c) newspaper or magazines registered with the Registrar of Newspapers;
(d) railway equipments or materials;
(e) agricultural produce;
(f) milk, salt and food grain including flours, pulses and rice; and
(g) organic manure.

Services provided by a goods transport agency, by way of transport in a goods carriage of -
(a) agricultural produce;
(b) goods, where consideration charged for the transportation of goods on a consignment transported in a single carriage does not exceed one thousand five hundred rupees;
(c) goods, where consideration charged for transportation of all such goods for a single consignee does not exceed rupees seven hundred and fifty;
(d) milk, salt and food grain including flour, pulses and rice;
(e) organic manure;
(f) newspaper or magazines registered with the Registrar of Newspapers;
(g) relief materials meant for victims of natural or man-made disasters, calamities, accidents or mishap; or
(h) defence or military equipments.

Services provided by a goods transport agency, by way of transport in a goods carriage of -
(a) agricultural produce;
(b) goods, where consideration charged for the transportation of goods on a consignment transported in a single carriage does not exceed one thousand five hundred rupees;
(c) goods, where consideration charged for transportation of all such goods for a single consignee does not exceed rupees seven hundred and fifty;
(d) milk, salt and food grain including flour, pulses and rice;
(e) organic manure;
(f) newspaper or magazines registered with the Registrar of Newspapers;
(g) relief materials meant for victims of natural or man-made disasters, calamities, accidents or mishap; or
(h) defence or military equipments.

Services provided by a goods transport agency to an unregistered person, including an unregistered casual taxable person, other than the following recipients, namely: -
(a) any factory registered under or governed by the Factories Act, 1948 (63 of 1948); or
(b) any Society registered under the Societies Registration Act, 1860 (21 of 1860) or under any other law for the time being in force in any part of India; or
(c) any Co-operative Society established by or under any law for the time being in force; or
(d) any body corporate established, by or under any law for the time being in force; or
(e) any partnership firm whether registered or not under any law including association of persons;
(f) any casual taxable person registered under the Central Goods and Services Tax Act or the Integrated Goods and Services Tax Act or the State Goods and Services Tax Act or the Union Territory Goods and Services Tax Act.

Services provided by a goods transport agency to an unregistered person, including an unregistered casual taxable person, other than the following recipients, namely: -
(a) any factory registered under or governed by the Factories Act, 1948 (63 of 1948); or
(b) any Society registered under the Societies Registration Act, 1860 (21 of 1860) or under any other law for the time being in force in any part of India; or
(c) any Co-operative Society established by or under any law for the time being in force; or
(d) any body corporate established, by or under any law for the time being in force; or
(e) any partnership firm whether registered or not under any law including association of persons;
(f) any casual taxable person registered under the Central Goods and Services Tax Act or the Integrated Goods and Services Tax Act or the State Goods and Services Tax Act or the Union Territory Goods and Services Tax Act.

Services provided by a goods transport agency, by way of transport of goods in a goods carriage, to, -
(a) a Department or Establishment of the Central Government or State Government or Union territory; or
(b) local authority; or
(c) Governmental agencies,
which has taken registration under the Central Goods and Services Tax Act, 2017 (12 of 2017) only for the purpose of deducting tax under Section 51 and not for making a taxable supply of goods or services.

Services provided by a goods transport agency, by way of transport of goods in a goods carriage, to, -
(a) a Department or Establishment of the Central Government or State Government or Union territory; or
(b) local authority; or
(c) Governmental agencies,
which has taken registration under the Central Goods and Services Tax Act, 2017 (12 of 2017) only for the purpose of deducting tax under Section 51 and not for making a taxable supply of goods or services.

Services by way of giving on hire –
(a) to a state transport undertaking, a motor vehicle meant to carry more than twelve passengers; or
(aa) to a local authority, an Electrically operated vehicle meant to carry more than twelve passengers; or
Explanation.- For the purposes of this entry, “Electrically operated vehicle” means vehicle falling under Chapter 87 in the First Schedule to the Customs Tariff Act, 1975 (51 of 1975) which is run solely on electrical energy derived from an external source or from one or more electrical batteries fitted to such road vehicle.
(b) to a goods transport agency, a means of transportation of goods.
(c) motor vehicle for transport of students, faculty and staff, to a person providing services of transportation of students, faculty and staff to an educational institution providing services by way of pre-school education and education upto higher secondary school or equivalent.

Services by way of giving on hire –
(a) to a state transport undertaking, a motor vehicle meant to carry more than twelve passengers; or
(aa) to a local authority, an Electrically operated vehicle meant to carry more than twelve passengers; or
Explanation.- For the purposes of this entry, “Electrically operated vehicle” means vehicle falling under Chapter 87 in the First Schedule to the Customs Tariff Act, 1975 (51 of 1975) which is run solely on electrical energy derived from an external source or from one or more electrical batteries fitted to such road vehicle.
(b) to a goods transport agency, a means of transportation of goods.
(c) motor vehicle for transport of students, faculty and staff, to a person providing services of transportation of students, faculty and staff to an educational institution providing services by way of pre-school education and education upto higher secondary school or equivalent.

Service by way of access to a road or a bridge on payment of toll charges.

Service by way of access to a road or a bridge on payment of annuity.

Services by way of loading, unloading, packing, storage or warehousing of rice.

Services by way of loading, unloading, packing, storage or warehousing of rice.

Services by way of warehousing of minor forest produce.

Services by way of warehousing of minor forest produce.

Services by way of storage or warehousing of cereals, pulses, fruits, nuts and vegetables, spices, copra, sugarcane, jaggery, raw vegetable fibres such as cotton, flax, jute etc., indigo, unmanufactured tobacco, betel leaves, tendu leaves, coffee and tea.

Services by way of storage or warehousing of cereals, pulses, fruits, nuts and vegetables, spices, copra, sugarcane, jaggery, raw vegetable fibres such as cotton, flax, jute etc., indigo, unmanufactured tobacco, betel leaves, tendu leaves, coffee and tea.

Transmission or distribution of electricity by an electricity transmission or distribution utility.

Services by the Reserve Bank of India.

Services by way of—
(a) extending deposits, loans or advances in so far as the consideration is represented by way of interest or discount (other than interest involved in credit card services);
(b) inter se sale or purchase of foreign currency amongst banks or authorised dealers of foreign exchange or amongst banks and such dealers.

Services provided by a banking company to Basic Saving Bank Deposit (BSBD) account holders under Pradhan Mantri Jan Dhan Yojana (PMJDY).

Services of life insurance business provided by way of annuity under the National Pension System regulated by the Pension Fund Regulatory and Development Authority of India under the Pension Fund Regulatory and Development Authority Act, 2013 (23 of 2013).

Services of life insurance business provided by way of annuity under the National Pension System regulated by the Pension Fund Regulatory and Development Authority of India under the Pension Fund Regulatory and Development Authority Act, 2013 (23 of 2013).

Services of life insurance business provided or agreed to be provided by the Army, Naval and Air Force Group Insurance Funds to members of the Army, Navy and Air Force, respectively, under the Group Insurance Schemes of the Central Government.

Services of life insurance business provided or agreed to be provided by the Army, Naval and Air Force Group Insurance Funds to members of the Army, Navy and Air Force, respectively, under the Group Insurance Schemes of the Central Government.

Services of life insurance provided or agreed to be provided by the Naval Group Insurance Fund to the personnel of Coast Guard under the Group Insurance Schemes of the Central Government.

Services of life insurance provided or agreed to be provided by the Naval Group Insurance Fund to the personnel of Coast Guard under the Group Insurance Schemes of the Central Government.

Services of life insurance provided or agreed to be provided by the Central Armed Police Forces (under Ministry of Home Affairs) Group Insurance Funds to their members under the Group Insurance Schemes of the concerned Central Armed Police Force.

Services of life insurance provided or agreed to be provided by the Central Armed Police Forces (under Ministry of Home Affairs) Group Insurance Funds to their members under the Group Insurance Schemes of the concerned Central Armed Police Force.

Services by the Employees’ State Insurance Corporation to persons governed under the Employees’ State Insurance Act, 1948 (34 of 1948).

Services by the Employees’ State Insurance Corporation to persons governed under the Employees’ State Insurance Act, 1948 (34 of 1948).

Services provided by the Employees Provident Fund Organisation to the persons governed under the Employees Provident Funds and the Miscellaneous Provisions Act, 1952 (19 of 1952).

Services by Coal Mines Provident Fund Organisation to persons governed by the Coal Mines Provident Fund and Miscellaneous Provisions Act, 1948 (46 of 1948).

Services by Coal Mines Provident Fund Organisation to persons governed by the Coal Mines Provident Fund and Miscellaneous Provisions Act, 1948 (46 of 1948).

Services by National Pension System (NPS) Trust to its members against consideration in the form of administrative fee.

Services by National Pension System (NPS) Trust to its members against consideration in the form of administrative fee.

Services provided by the Insurance Regulatory and Development Authority of India to insurers under the Insurance Regulatory and Development Authority of India Act, 1999 (41 of 1999).

Services provided by the Securities and Exchange Board of India set up under the Securities and Exchange Board of India Act, 1992 (15 of 1992) by way of protecting the interests of investors in securities and to promote the development of, and to regulate, the securities market.

Services by an acquiring bank, to any person in relation to settlement of an amount upto two thousand rupees in a single transaction transacted through credit card, debit card, charge card or other payment card service.
Explanation.— For the purposes of this entry, “acquiring bank” means any banking company, financial institution including non-banking financial company or any other person, who makes the payment to any person who accepts such card.

Services supplied by Central Government, State Government, Union territory to their undertakings or Public Sector Undertakings(PSUs) by way of guaranteeing the loans taken by such undertakings or PSUs from the banking companies and financial institutions.

Services of general insurance business provided under following schemes –
(a) Hut Insurance Scheme;
(b) Cattle Insurance under Swarnajaynti Gram SwarozgarYojna (earlier known as Integrated Rural Development Programme);
(c) Scheme for Insurance of Tribals;
(d) Janata Personal Accident Policy and Gramin Accident Policy;
(e) Group Personal Accident Policy for Self-Employed Women;
(f) Agricultural Pumpset and Failed Well Insurance;
(g) premia collected on export credit insurance;
(h) Restructured Weather Based Crop Insurance Scheme (RWCIS), approved by the Government of India and implemented by the Ministry of Agriculture;
(i) Jan ArogyaBima Policy;
(j) Pradhan MantriFasalBimaYojana (PMFBY);
(k) Pilot Scheme on Seed Crop Insurance;
(l) Central Sector Scheme on Cattle Insurance;
(m) Universal Health Insurance Scheme;
(n) RashtriyaSwasthyaBimaYojana;
(o) Coconut Palm Insurance Scheme;
(p) Pradhan Mantri Suraksha BimaYojna;
(q) Niramaya Health Insurance Scheme implemented by the Trust constituted under the provisions of the National Trust for the Welfare of Persons with Autism, Cerebral Palsy, Mental Retardation and Multiple Disabilities Act, 1999 (44 of 1999);
(r) Bangla Shasya Bima

Services of general insurance business provided under following schemes –
(a) Hut Insurance Scheme;
(b) Cattle Insurance under Swarnajaynti Gram SwarozgarYojna (earlier known as Integrated Rural Development Programme);
(c) Scheme for Insurance of Tribals;
(d) Janata Personal Accident Policy and Gramin Accident Policy;
(e) Group Personal Accident Policy for Self-Employed Women;
(f) Agricultural Pumpset and Failed Well Insurance;
(g) premia collected on export credit insurance;
(h) Restructured Weather Based Crop Insurance Scheme (RWCIS), approved by the Government of India and implemented by the Ministry of Agriculture;
(i) Jan ArogyaBima Policy;
(j) Pradhan MantriFasalBimaYojana (PMFBY);
(k) Pilot Scheme on Seed Crop Insurance;
(l) Central Sector Scheme on Cattle Insurance;
(m) Universal Health Insurance Scheme;
(n) RashtriyaSwasthyaBimaYojana;
(o) Coconut Palm Insurance Scheme;
(p) Pradhan Mantri Suraksha BimaYojna;
(q) Niramaya Health Insurance Scheme implemented by the Trust constituted under the provisions of the National Trust for the Welfare of Persons with Autism, Cerebral Palsy, Mental Retardation and Multiple Disabilities Act, 1999 (44 of 1999);
(r) Bangla Shasya Bima

Services of life insurance business provided under following schemes-
(a) JanashreeBimaYojana;
(b) AamAadmiBimaYojana;
(c) Life micro-insurance product as approved by the Insurance Regulatory and Development Authority, having maximum amount of cover of two lakhs rupees;
(d) Varishtha Pension BimaYojana;
(e) Pradhan Mantri Jeevan Jyoti Bima Yojana;
(f) Pradhan Mantri Jan DhanYogana;
(g) Pradhan MantriVayaVandanYojana.

Services of life insurance business provided under following schemes-
(a) JanashreeBimaYojana;
(b) AamAadmiBimaYojana;
(c) Life micro-insurance product as approved by the Insurance Regulatory and Development Authority, having maximum amount of cover of two lakhs rupees;
(d) Varishtha Pension BimaYojana;
(e) Pradhan Mantri Jeevan Jyoti Bima Yojana;
(f) Pradhan Mantri Jan DhanYogana;
(g) Pradhan MantriVayaVandanYojana.

Services by way of reinsurance ofthe insurance schemes specified in serial number 35 or 36 or 40.

Services by way of reinsurance ofthe insurance schemes specified in serial number 35 or 36 or 40.

Services by way of collection of contribution under the Atal Pension Yojana.

Services by way of collection of contribution under the Atal Pension Yojana.

Services by way of collection of contribution under any pension scheme of the State Governments.

Services by way of collection of contribution under any pension scheme of the State Governments.

Services by the folowing persons in respective capacities –
(a) business facilitator or a business correspondent to a banking company with respect to accounts in its rural area branch;
(b) any person as an intermediary to a business facilitator or a business correspondent with respect to services mentioned in entry (a); or
(c) business facilitator or a business correspondent to an insurance company in a rural area.

Services by the folowing persons in respective capacities –
(a) business facilitator or a business correspondent to a banking company with respect to accounts in its rural area branch;
(b) any person as an intermediary to a business facilitator or a business correspondent with respect to services mentioned in entry (a); or
(c) business facilitator or a business correspondent to an insurance company in a rural area.

Services by an intermediary of financial services located in a multi services SEZ with International Financial Services Centre (IFSC) status to a customer located outside India for international financial services in currencies other than Indian rupees (INR).
Explanation.- For the purposes of this entry, the intermediary of financial services in IFSC is a person,-
(i) who is permitted or recognised as such by the Government of India or any Regulator appointed for regulation of IFSC;or
(ii) who is treated as a person resident outside India under the Foreign Exchange Management (International Financial Services Centre) Regulations, 2015; or
(iii) who is registered under the Insurance Regulatory and Development Authority of India (International Financial Service Centre) Guidelines, 2015 as IFSC Insurance Office; or
(iv) who is permitted as such by Securities and Exchange Board of India (SEBI) under the Securities and Exchange Board of India (International Financial Services Centres) Guidelines, 2015.

Services provided to the Central Government, State Government, Union territory under any insurance scheme for which total premium is paid by the Central Government, State Government, Union territory.

Services provided to the Central Government, State Government, Union territory under any insurance scheme for which total premium is paid by the Central Government, State Government, Union territory.

Upfront amount (called as premium, salami, cost, price, development charges or by any other name) payable in respect of service by way of granting of long term lease of thirty years, or more) of industrial plots or plots for development of infrastructure for financial business, provided by the State Government Industrial Development Corporations or Undertakings or by any other entity having 20 per cent. or more ownership of Central Government, State Government, Union territory to the industrial units or the developers in any industrial or financial business area.

Explanation.- For the purpose of this exemption, the Central Government, State Government or Union territory shall have 20 per cent. or more ownership in the entity directly or through an entity which is wholly owned by the Central Government, State Government or Union territory.

“Provided that the leased plots shall be used for the purpose for which they are allotted, that is, for industrial or financial activity in an industrial or financial business area:
Provided further that the State Government concerned shall monitor and enforce the above condition as per the order issued by the State Government in this regard:
Provided also that in case of any violation or subsequent change of land use, due to any reason whatsoever, the original lessor, original lessee as well as any subsequent lessee or buyer or owner shall be jointly and severally liable to pay such amount of central tax, as would have been payable on the upfront amount charged for the long term lease of the plots but for the exemption contained herein, along with the applicable interest and penalty:
Provided also that the lease agreement entered into by the original lessor with the original lessee or subsequent lessee, or sub- lessee, as well as any subsequent lease or sale agreements, for lease or sale of such plots to subsequent lessees or buyers or owners shall incorporate in the terms and conditions, the fact that the central tax was exempted on the long term lease of the plots by the original lessor to the original lessee subject to above condition and that the parties to the said agreements undertake to comply with the same.”.

Service by way of transfer of development rights (herein refer TDR) or Floor Space Index (FSI) (including additional FSI) on or after 1st April, 2019 for construction of residential apartments by a promoter in a project, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
The amount of GST exemption available for construction of residential apartments in the project under this notification shall be calculated as under:
[GST payable on TDR or FSI (including additional FSI) or both for construction of the project] x (carpet area of the residential apartments in the project ÷ Total carpet area of the residential and commercial apartments in the project )

Provided that the promoter shall be liable to pay tax at the applicable rate, on reverse charge basis, on such proportion of value of development rights, or FSI (including additional FSI), or both, as is attributable to the residential apartments, which remain un-booked on the date of issuance of completion certificate, or first occupation of the project, as the case may be, in the following manner -
[GST payable on TDR or FSI (including additional FSI) or both for construction of the residential apartments in the project but for the exemption contained herein] x (carpet area of the residential apartments in the project which remain un- booked on the date of issuance of completion certificate or first occupation ÷ Total carpet area of the residential apartments in the project)
Provided further that tax payable in terms of the first proviso hereinabove shall not exceed 0.5 per cent. of the value in case of affordable residential apartments and 2.5 per cent. of the value in case of residential apartments other than affordable residential apartments remaining un- booked on the date of issuance of completion certificate or first occupation The liability to pay central tax on the said portion of the development rights or FSI, or both, calculated as above, shall arise on the date of completion or first occupation of the project, as the case may be, whichever is earlier.

Upfront amount (called as premium, salami, cost, price, development charges or by any other name) payable in respect of service by way of granting of long term lease of thirty years, or more, on or after 01.04.2019, for construction of residential apartments by a promoter in a project, intended for sale to a buyer, wholly or partly, except where the entire consideration has been received after issuance of completion certificate, where required, by the competent authority or after its first occupation, whichever is earlier.
The amount of GST exemption available for construction of residential apartments in the project under this notification shall be calculated as under:
[GST payable on upfront amount (called as premium, salami, cost, price, development charges or by any other name) payable for long term lease of land for construction of the project] x (carpet area of the residential apartments in the project ÷ Total carpet area of the residential and commercial apartments in the project).

Provided that the promoter shall be liable to pay tax at the applicable rate, on reverse charge basis, on such proportion of upfront amount (called as premium, salami, cost, price, development charges or by any other name) paid for long term lease of land, as is attributable to the residential apartments, which remain un- booked on the date of issuance of completion certificate, or first occupation of the project, as the case may be, in the following manner -
[GST payable on upfront amount (called as premium, salami, cost, price, development charges or by any other name) payable for long term lease of land for construction of the residential apartments in the project but for the exemption contained herein] x (carpet area of the residential apartments in the project which remain un- booked on the date of issuance of completion certificate or first occupation ÷ Total carpet area of the residential apartments in the project);
Provided further that the tax payable in terms of the first proviso shall not exceed 0.5 per cent. of the value in case of affordable residential apartments and 2.5 per cent. of the value in case of residential apartments other than affordable residential apartments remaining un- booked on the date of issuance of completion certificate or first occupation. The liability to pay central tax on the said proportion of upfront amount (called as premium, salami, cost, price, development charges or by any other name) paid for long term lease of land, calculated as above, shall arise on the date of issue of completion certificate or first occupation of the project, as the case may be.

Services provided by the Central Government, State Government, Union territory or local authority by way of allowing a business entity to operate as a telecom service provider or use radio frequency spectrum during the period prior to the 1stApril, 2016, on payment of licence fee or spectrum user charges, as the case may be.

Services provided by the Central Government, State Government, Union territory or local authority by way of allowing a business entity to operate as a telecom service provider or use radio frequency spectrum during the period prior to the 1stApril, 2016, on payment of licence fee or spectrum user charges, as the case may be.

Services of leasing of assets (rolling stock assets including wagons, coaches, locos) by the Indian Railways Finance Corporation to Indian Railways.

Services provided by an incubatee up to a total turnover of fifty lakh rupees in a financial year subject to the following conditions, namely:-
(a) the total turnover had not exceeded fifty lakh rupees during the preceding financial year; and
(b) a period of three years has not elapsed from the date of entering into an agreement as an incubatee.

Services provided by-
(a) (a) an arbitral tribunal to –
(i) any person other than a business entity; or
(ii) a business entity with an aggregate turnover up to such amount in the preceding financial year as makes it eligible for exemption from registration under the Central Goods and Services Tax Act, 2017 (12 of 2017);
(iii) the Central Government, State Government, Union territory, local authority, Governmental Authority or Government Entity;
(b) a partnership firm of advocates or an individual as an advocate other than a senior advocate, by way of legal services to-
(i) an advocate or partnership firm of advocates providing legal services;
(ii) any person other than a business entity; or
(iii) a business entity with an aggregate turnover up to such amount in the preceding financial year as makes it eligible for exemption from registration under the Central Goods and Services Tax Act, 2017 (12 of 2017);
(iv) the Central Government, State Government, Union territory, local authority, Governmental Authority or Government Entity;
(c) a senior advocate by way of legal services to-
(i) any person other than a business entity; or
(ii) a business entity with an aggregate turnover up to such amount in the preceding financial year as makes it eligible for exemption from registration under the Central Goods and Services Tax Act, 2017 (12 of 2017);
(iii) the Central Government, State Government, Union territory, local authority, Governmental Authority or Government Entity.

Services provided by-
(a) (a) an arbitral tribunal to –
(i) any person other than a business entity; or
(ii) a business entity with an aggregate turnover up to such amount in the preceding financial year as makes it eligible for exemption from registration under the Central Goods and Services Tax Act, 2017 (12 of 2017);
(iii) the Central Government, State Government, Union territory, local authority, Governmental Authority or Government Entity;
(b) a partnership firm of advocates or an individual as an advocate other than a senior advocate, by way of legal services to-
(i) an advocate or partnership firm of advocates providing legal services;
(ii) any person other than a business entity; or
(iii) a business entity with an aggregate turnover up to such amount in the preceding financial year as makes it eligible for exemption from registration under the Central Goods and Services Tax Act, 2017 (12 of 2017);
(iv) the Central Government, State Government, Union territory, local authority, Governmental Authority or Government Entity;
(c) a senior advocate by way of legal services to-
(i) any person other than a business entity; or
(ii) a business entity with an aggregate turnover up to such amount in the preceding financial year as makes it eligible for exemption from registration under the Central Goods and Services Tax Act, 2017 (12 of 2017);
(iii) the Central Government, State Government, Union territory, local authority, Governmental Authority or Government Entity.

Services by a veterinary clinic in relation to health care of animals or birds.

Services provided by the Central Government, State Government, Union territory or local authority by way of-
(a) registration required under any law for the time being in force;
(b) testing, calibration, safety check or certification relating to protection or safety of workers, consumers or public at large, including fire license, required under any law for the time being in force.

Services provided by the Central Government, State Government, Union territory or local authority by way of-
(a) registration required under any law for the time being in force;
(b) testing, calibration, safety check or certification relating to protection or safety of workers, consumers or public at large, including fire license, required under any law for the time being in force.

Services by way of licensing, registration and analysis or testing of food samples supplied by the Food Safety and Standards Authority of India (FSSAI) to Food Business Operators.

Services by way of licensing, registration and analysis or testing of food samples supplied by the Food Safety and Standards Authority of India (FSSAI) to Food Business Operators.

Taxable services, provided or to be provided, by a Technology Business Incubator or a Science and Technology Entrepreneurship Park recognised by the National Science and Technology Entrepreneurship Development Board of the Department of Science and Technology, Government of India or bio-incubators recognised by the Biotechnology Industry Research Assistance Council, under the Department of Biotechnology, Government of India.

Services by way of collecting or providing news by an independent journalist, Press Trust of India or United News of India.

Services of public libraries by way of lending of books, publications or any other knowledge-enhancing content or material.

Services provided by the Goods and Services Tax Network to the Central Government or State Governments or Union territories for implementation of Goods and Services Tax.

Services by an organiser to any person in respect of a business exhibition held outside India.

Services by way of sponsorship of sporting events organised -
(a) by a national sports federation, or its affiliated federations, where the participating teams or individuals represent any district, State, zone or Country;
(b) by Association of Indian Universities, Inter-University Sports Board, School Games Federation of India, All India Sports Council for the Deaf, Paralympic Committee of India or Special Olympics Bharat;
(c) by the Central Civil Services Cultural and Sports Board;
(d) as part of national games, by the Indian Olympic Association; or
(e) under the Panchayat YuvaKreedaAur Khel Abhiyaan Scheme.

Services by way of fumigation in a warehouse of agricultural produce.

Service by an unincorporated body or a non- profit entity registered under any law for the time being in force, to its own members by way of reimbursement of charges or share of contribution –
(a) as a trade union;
(b) for the provision of carrying out any activity which is exempt from the levy of Goods and service Tax; or
(c) up to an amount of seven thousand five hundred rupees per month per member for sourcing of goods or services from a third person for the common use of its members in a housing society or a residential complex.

Services provided by an unincorporated body or a non-profit entity registered under any law for the time being in force, engaged in,- (i) activities relating to the welfare of industrial or agricultural labour or farmers; or (ii) promotion of trade, commerce, industry, agriculture, art, science, literature, culture, sports, education, social welfare, charitable activities and protection of environment, to its own members against consideration in the form of membership fee upto an amount of one thousand rupees (Rs 1000/-) per member per year.

Services relating to cultivation of plants and rearing of all life forms of animals, except the rearing of horses, for food, fibre, fuel, raw material or other similar products or agricultural produce by way of—
(a) agricultural operations directly related to production of any agricultural produce including cultivation, harvesting, threshing, plant protection or testing;
(b) supply of farm labour;
(c) processes carried out at an agricultural farm including tending, pruning, cutting, harvesting, drying, cleaning, trimming, sun drying, fumigating, curing, sorting, grading, cooling or bulk packaging and such like operations which do not alter the essential characteristics of agricultural produce but make it only marketable for the primary market;
(d) renting or leasing of agro machinery or vacant land with or without a structure incidental to its use;
(e) loading, unloading, packing, storage or warehousing of agricultural produce;
(f) agricultural extension services;
(g) services by any Agricultural Produce Marketing Committee or Board or services provided by a commission agent for sale or purchase of agricultural produce;
(h) services by way of fumigation in a warehouse of agricultural produce.

Carrying out an intermediate production process as job work in relation to cultivation of plants and rearing of all life forms of animals, except the rearing of horses, for food, fibre, fuel, raw material or other similar products or agricultural produce.

Services by way of artificial insemination of livestock (other than horses).

Services by way of slaughtering of animals.

Services by way of pre-conditioning, pre-cooling, ripening, waxing, retail packing, labelling of fruits and vegetables which do not change or alter the essential characteristics of the said fruits or vegetables.

Services provided by the National Centre for Cold Chain Development under the Ministry of Agriculture, Cooperation and Farmer’s Welfare by way of cold chain knowledge dissemination.

Services provided by the National Centre for Cold Chain Development under the Ministry of Agriculture, Cooperation and Farmer’s Welfare by way of cold chain knowledge dissemination.

Services by a foreign diplomatic mission located in India.

Services by a specified organisation in respect of a religious pilgrimage facilitated by the Government of India, under bilateral arrangement.

Services provided by the Central Government, State Government, Union territory or local authority by way of issuance of passport, visa, driving licence, birth certificate or death certificate.

Services provided by the Central Government, State Government, Union territory or local authority by way of tolerating non-performance of a contract for which consideration in the form of fines or liquidated damages is payable to the Central Government, State Government, Union territory or local authority under such contract.

Services provided by the Central Government, State Government, Union territory or local authority by way of tolerating non-performance of a contract for which consideration in the form of fines or liquidated damages is payable to the Central Government, State Government, Union territory or local authority under such contract.

Services provided by the Central Government, State Government, Union territory or local authority by way of assignment of right to use natural resources to an individual farmer for cultivation of plants and rearing of all life forms of animals, except the rearing of horses, for food, fibre, fuel, raw material or other similar products.

Services provided by the Central Government, State Government, Union territory or local authority by way of assignment of right to use any natural resource where such right to use was assigned by the Central Government, State Government, Union territory or local authority before the 1st April, 2016:
Provided that the exemption shall apply only to tax payable on one time charge payable, in full upfront or in instalments, for assignment of right to use such natural resource.

Services provided by the Central Government, State Government, Union territory or local authority by way of assignment of right to use any natural resource where such right to use was assigned by the Central Government, State Government, Union territory or local authority before the 1st April, 2016:
Provided that the exemption shall apply only to tax payable on one time charge payable, in full upfront or in instalments, for assignment of right to use such natural resource.

Services provided by the Central Government, State Government, Union territory by way of deputing officers after office hours or on holidays for inspection or container stuffing or such other duties in relation to import export cargo on payment of Merchant Overtime charges.

Services by way of providing information under the Right to Information Act, 2005 (22 of 2005).

Services supplied by a State Government to Excess Royalty Collection Contractor (ERCC) by way of assigning the right to collect royalty on behalf of the State Government on the mineral dispatched by the mining lease holders. Explanation.- “mining lease holder” means a person who has been granted mining lease, quarry lease or license or other mineral concession under the Mines and Minerals (Development and Regulation) Act, 1957 (67 of 1957), the rules made thereunder or the rules made by a State Government under sub-section (1) of section 15 of the Mines and Minerals (Development and Regulation) Act, 1957.

Provided that at the end of the contract period, ERCC shall submit an account to the State Government and certify that the amount of goods and services tax deposited by mining lease holders on royalty is more than the goods and services tax exempted on the service provided by State Government to the ERCC of assignment of right to collect royalty and where such amount of goods and services tax paid by mining lease holders is less than the amount of goods and services tax exempted, the exemption shall be restricted to such amount as is equal to the amount of goods and services tax paid by the mining lease holders and the ERCC shall pay the difference between goods and services tax exempted on the service provided by State Government to the ERCC of assignment of right to collect royalty and goods and services tax paid by the mining lease holders on royalty.”;

Services by an artist by way of a performance in folk or classical art forms of-
(a) music, or
(b) dance, or
(c) theatre,
if the consideration charged for such performance is not more than one lakh and fifty thousand rupees:
Provided that the exemption shall not apply to service provided by such artist as a brand ambassador.

Services by way of admission to a museum, national park, wildlife sanctuary, tiger reserve or zoo.

Services by way of admission to a protected monument so declared under the Ancient Monuments and Archaeological Sites and Remains Act 1958 (24 of 1958) or any of the State Acts, for the time being in force.

Services provided -
(a) by an educational institution to its students, faculty and staff;
(aa) by an educational institution by way of conduct of entrance examination against consideration in the form of entrance fee;
(b) to an educational institution, by way of, -
(i) transportation of students, faculty and staff;
(ii) catering, including any mid-day meals scheme sponsored by the Central Government, State Government or Union territory;
(iii) security or cleaning or house-keeping services performed in such educational institution;
(iv) services relating to admission to, or conduct of examination by, such institution;
(v) supply of online educational journals or periodicals:
Provided that nothing contained in sub-items (i), (ii) and (iii) of item (b) shall apply to an educational institution other than an institution providing services by way of pre-school education and education up to higher secondary school or equivalent.

Provided further that nothing contained in sub-item (v) of item (b) shall apply to an institution providing services by way of,-
(i) pre-school education and education up to higher secondary school or equivalent; or
(ii) education as a part of an approved vocational education course.

Services provided -
(a) by an educational institution to its students, faculty and staff;
(aa) by an educational institution by way of conduct of entrance examination against consideration in the form of entrance fee;
(b) to an educational institution, by way of, -
(i) transportation of students, faculty and staff;
(ii) catering, including any mid-day meals scheme sponsored by the Central Government, State Government or Union territory;
(iii) security or cleaning or house-keeping services performed in such educational institution;
(iv) services relating to admission to, or conduct of examination by, such institution;
(v) supply of online educational journals or periodicals:
Provided that nothing contained in sub-items (i), (ii) and (iii) of item (b) shall apply to an educational institution other than an institution providing services by way of pre-school education and education up to higher secondary school or equivalent.

Provided further that nothing contained in sub-item (v) of item (b) shall apply to an institution providing services by way of,-
(i) pre-school education and education up to higher secondary school or equivalent; or
(ii) education as a part of an approved vocational education course.

Services provided to a recognised sports body by-
(a) an individual as a player, referee, umpire, coach or team manager for participation in a sporting event organised by a recognized sports body;
(b) another recognised sports body.

Services provided to a recognised sports body by-
(a) an individual as a player, referee, umpire, coach or team manager for participation in a sporting event organised by a recognized sports body;
(b) another recognised sports body.

Any services provided by, _
(a) the National Skill Development Corporation set up by the Government of India;
(b) a Sector Skill Council approved by the National Skill Development Corporation;
(c) an assessment agency approved by the Sector Skill Council or the National Skill Development Corporation;
(d) a training partner approved by the National Skill Development Corporation or the Sector Skill Council, in relation to-
(i) the National Skill Development Programme implemented by the National Skill Development Corporation; or
(ii) a vocational skill development course under the National Skill Certification and Monetary Reward Scheme; or
(iii) any other Scheme implemented by the National Skill Development Corporation.

Any services provided by, _
(a) the National Skill Development Corporation set up by the Government of India;
(b) a Sector Skill Council approved by the National Skill Development Corporation;
(c) an assessment agency approved by the Sector Skill Council or the National Skill Development Corporation;
(d) a training partner approved by the National Skill Development Corporation or the Sector Skill Council, in relation to-
(i) the National Skill Development Programme implemented by the National Skill Development Corporation; or
(ii) a vocational skill development course under the National Skill Certification and Monetary Reward Scheme; or
(iii) any other Scheme implemented by the National Skill Development Corporation.

Any services provided by, _
(a) the National Skill Development Corporation set up by the Government of India;
(b) a Sector Skill Council approved by the National Skill Development Corporation;
(c) an assessment agency approved by the Sector Skill Council or the National Skill Development Corporation;
(d) a training partner approved by the National Skill Development Corporation or the Sector Skill Council, in relation to-
(i) the National Skill Development Programme implemented by the National Skill Development Corporation; or
(ii) a vocational skill development course under the National Skill Certification and Monetary Reward Scheme; or
(iii) any other Scheme implemented by the National Skill Development Corporation.

Services of assessing bodies empanelled centrally by the Directorate General of Training, Ministry of Skill Development and Entrepreneurship by way of assessments under the Skill Development Initiative Scheme.

Services of assessing bodies empanelled centrally by the Directorate General of Training, Ministry of Skill Development and Entrepreneurship by way of assessments under the Skill Development Initiative Scheme.

Services of assessing bodies empanelled centrally by the Directorate General of Training, Ministry of Skill Development and Entrepreneurship by way of assessments under the Skill Development Initiative Scheme.

Services provided by training providers (Project implementation agencies) under DeenDayal Upadhyaya Grameen Kaushalya Yojana implemented by the Ministry of Rural Development, Government of India by way of offering skill or vocational training courses certified by the National Council for Vocational Training.

Services provided to the Central Government, State Government, Union territory administration under any training programme for which total expenditure is borne by the Central Government, State Government, Union territory administration.

Services provided by the cord blood banks by way of preservation of stem cells or any other service in relation to such preservation.

Services by way of-
(a) health care services by a clinical establishment, an authorised medical practitioner or para-medics;
(b) services provided by way of transportation of a patient in an ambulance, other than those specified in (a) above.

Services provided by operators of the common bio-medical waste treatment facility to a clinical establishment by way of treatment or disposal of bio-medical waste or the processes incidental thereto.

Services by way of public conveniences such as provision of facilities of bathroom, washrooms, lavatories, urinal or toilets.

Services by way of training or coaching in recreational activities relating to-
(a) arts or culture, or
(b) sports by charitable entities registered under section 12AA of the Income-tax Act.

Services by way of right to admission to-

(a) circus, dance, or theatrical performance including drama or ballet;
(b) award function, concert, pageant, musical performance or any sporting event other than a recognised sporting event;
(c) recognised sporting event;
(d) planetarium,
where the consideration for right to admission to the events or placesas referred to in items (a), (b), (c) or (d) above is not more than Rs 500 per person.

Services by way of right to admission to the events organised under FIFA U-17 World Cup 2017.

Services by way of right to admission to the events organised under FIFA U-17 Women's World Cup 2020.